Terms and conditions

Company: QuickHomes BuildTech Pvt. Ltd.
Office: Akshar Business Park, Plot 03, Sector 25, Vashi, Navi Mumbai, Maharashtra, India – 400703
CIN: U41003MH2025PTC448391
GSTIN: 27AABCQ1178R1ZT
Email: contact@qbtglobal.com

1. Introduction

Welcome to QuickHomes BuildTech Pvt. Ltd. (“QBT”, “we”, “our” or “us”), a company based in Navi Mumbai, India. We provide cold-formed steel construction (QuickHomes), turnkey interior design and execution (Design Studio) and custom furniture manufacturing (W&K).

By accessing our website, contacting our representatives or engaging our services, you agree to these terms and conditions. If you do not agree, please do not use our website or services.

2. Products and services

• We make every effort to ensure that descriptions, technical information and images are accurate. Minor variations may occur due to manufacturing, materials or site conditions. Some images on this website are design visualisations.
• Specific scope, specifications, timelines and warranties for each project are set out in the project quotation or agreement, which takes precedence over this website.
• We may modify, update or discontinue any product or service at any time without notice.

3. Quotations and orders

• All quotations issued by QBT are valid for 30 days unless otherwise specified.
• Orders are confirmed only on receipt of a purchase order or signed agreement and the advance payment under the agreed commercial terms.
• QBT may revise or cancel an order in the case of unforeseen restrictions, pricing errors or non-availability of materials.

4. Pricing and payments

• All prices are in Indian Rupees (INR) and are exclusive of GST, transportation and installation unless stated otherwise. “Starting from” prices on this website are indicative.
• Prices may change without notice due to changes in material costs, exchange rates, duties or supplier pricing, until confirmed in a quotation.
• Payment milestones are as set out in your quotation or agreement.
• Late payments may attract interest of 1.5% per month on outstanding balances.
• Payments must be made only through authorised banking channels in the company’s registered name.

5. Delivery, site and installation

• Delivery and installation schedules are indicative and depend on site readiness, access, approvals, weather and logistics.
• The customer must ensure site readiness, including access, power and water where required, before installation.
• Rescheduled or delayed visits caused by site unavailability may incur additional charges.
• Clients should report any visible damage or discrepancy in delivered items within 48 hours of receipt.

6. Warranty and liability

• Warranties are as stated in your project quotation or agreement. QuickHomes structures carry a structural warranty as specified for each project, and third-party products carry the manufacturer’s warranty.
• Warranty does not cover damage due to mishandling, alterations by others, improper use, power fluctuations or natural wear and tear.
• QBT is not liable for indirect, incidental or consequential losses such as downtime, loss of profits or loss of business.

7. Cancellations

• Cancellations after order confirmation may attract a cancellation fee of up to 25% of the order value.
• Custom-made, made-to-order or imported-on-demand items are non-cancellable and non-returnable once production or procurement has begun.

8. Intellectual property

All logos, trademarks, designs, drawings, text and media on this website are the property of QuickHomes BuildTech Pvt. Ltd. or its suppliers. You may not copy, reproduce, distribute or display any content without prior written consent.

9. Confidentiality

All commercial and project-related information shared between QBT and its clients is confidential. Neither party will disclose it to a third party without written consent, except where required by law.

10. Limitation of liability

QBT is not liable for delays caused by third-party carriers, external contractors, authorities or events beyond our reasonable control, or for indirect or consequential damages. Our total liability is limited to the value of the goods or services supplied under the relevant order.

11. Governing law and jurisdiction

These terms are governed by the laws of India. Any disputes are subject to the exclusive jurisdiction of the courts in Mumbai, Maharashtra.

12. Amendments

QBT may amend or update these terms at any time. The latest version will always be available on this website.

Website use

Content. Information on this website is for general information only. While we strive for accuracy, we do not guarantee that it is complete, current or error-free, and we may update it without notice.

External links. This website may link to third-party websites. We are not responsible for their content, accuracy or privacy practices.

Data and cookies. See our privacy policy. By using this website, you consent to our standard data practices in line with applicable Indian data protection laws.